Legals for March, 14 2020

March 14, 2020 12:00 AM

NOTICE INVITING BIDS OWNER: Bonner County, Idaho 1500 Highway 2, Suite 308 Sandpoint, Idaho 83864 Separate sealed BIDS for the construction of: Obstruction Removal Priest River Airport, Priest River, Idaho will be received by the Owner at the Office of the Board of County Commissioners, Bonner County, Idaho, 1500 Highway 2, Suite 308, Sandpoint, Idaho 83864 until 1:00 p.m., Monday, March 31, 2020 and then at said location and time, publicly opened and read aloud. Work associated with proposed improvements is generally described as follows: SCHEDULE A:Obstruction Removal Work generally consists of removing trees identified on the plans and replanting replacement trees. Approximate quantities include: removing 21 trees, stump grinding 36 trees, and planting 45 small trees. Other work includes installing traffic control, topsoiling, seeding, and other items. The Contract Documents are available for examination at the office of the Engineer, T-O Engineers, 7950 Meadowlark Way, Suite A, Coeur d'Alene, Idaho 83815. The Contract Documents will be made available after 2:00 p.m., Monday , March 16, 2020. Interested bidders may obtain bid documents at www.to-engineersplanroom.com. Bid documents may be ordered in hard copy format for purchase at cost (nonrefundable). Electronic documents in PDF format may be downloaded for no cost. To automatically receive addenda, bidders must download or order hard copies through www.to-engineersplanroom.com. A Prebid Conference will be held at 1:00 p.m., Wednesday, March 25, 2020 at the Priest River Airport Pilots Lounge, 102 Airfield Way, Priest River, Idaho. Attendance is highly recommended, not mandatory. A Bid Guaranty, payable in cash, by cashiers check, certified check or bid bond, of 5 percent of the BID AMOUNT is required. Separate Performance and Payment Bonds each in the amount of 100 percent of the CONTRACT AMOUNT will be required. Each bidder must supply all the information required by the Bid Documents and Specifications. This Public Works Project is financed in part by Federal Aid Funds. No contractor, subcontractor, or specialty contractor shall be required to have a current license as a Contractor in the State of Idaho in order to submit a bid or proposal on this project; prior to award and execution of the Contract, the successful bidder shall secure a Idaho Public Works Contractor's License. Prospective Contractors are notified that the work under this Contract is funded in part by a grant from the Federal Aviation Administration and as such is subject to Executive Order 11246, 41 CFR Part 60-4, and Equal Employment Opportunity (EEO) and Federal Labor Provisions. The Contractor will be required to comply with all applicable Federal and State Equal Employment Opportunity Laws and Regulations. To be eligible for award, the Contractor must agree to comply with the Affirmative Action Requirements and Minimum Wage Rates identified in the Contract Documents. Prospective Contractors are notified that work under this Contract is funded in part by a grant from the Federal Aviation Administration and as such this solicitation and any resulting contract are subject to the requirements of the Buy American Preference; Civil Rights-Title VI Assurance; Davis Bacon; Debarment and Suspension; Disadvantaged Business Enterprise; Foreign Trade Restriction; Lobbying and Influencing Federal Employees; and Recovered Materials Contract Provisions under the Solid Waste Disposal Act. For DOT-assisted contracts during Federal Fiscal Years 2018/2019/2020 (10/1/2017)-9/30/2020), Priest River Airport has adopted an overall three-year DBE goal of 2.40% (0.0% Race Conscious and 2.40% Race Neutral). This solicitation and any resulting contract are subject to the Buy America requirements of 49 U.S.C. Section 50101. This solicitation and any resulting contract are subject to the Trade Restriction Clause 49 CFR Part 30 and 49 USC Section 50104. This project is a public improvement subject to the prevailing wage requirements of the Davis-Bacon Act 2 CFR Part 200, Appendix II (D) and 29 CFR Part 5. By submitting a bid/proposal under this solicitation, the bidder or offer certifies that neither it nor its principals are presently debarred or suspended by any Federal department or agency from participation in this transaction. This contract is covered by the Drug Free Workplace Act of 1988. All Contractors subject to the Drug-Free Workplace Act of 1988 are required to provide a drug-free workplace. Bonner County, Idaho (Priest River Airport), in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award. The requirements of 49 CFR part 26 apply to this contract. It is the policy of Bonner County, Idaho (Priest River Airport) to practice nondiscrimination based on race, color, sex or national origin in the award or performance of this contract. The Owner encourages participation by all firms qualifying under this solicitation regardless of business size or ownership. All prospective bidders are directed to the Instructions for Bidders for discussion of Bid policies, procedures, and requirements. The Owner reserves the right to reject any and all Bids, to waive any and all informalities and to negotiate contract terms with the successful Bidder, and the right to disregard all non-conforming, non-responsive or conditional Bids. Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity: 1. The Offeror's or Bidder's attention is called to the "Equal Opportunity Clause" and the "Standard Federal Equal Employment Opportunity Construction Contract Specifications" set forth herein. 2. The goals and timetables for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows: Goals for minority participation for each trade 3.0% Goals for female participation in each trade 6.9% These goals are applicable to all of the Contractor's construction work (whether or not it is Federal or federally assisted) performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, it shall apply the goals established for such geographical area where the work is actually performed. With regard to this second area, the Contractor also is subject to the goals for both its federally involved and non-federally involved construction. The Contractor's compliance with the Executive Order and the regulations in 41 CFR Part 60-4 shall be based on its implementation of the Equal Opportunity Clause, specific affirmative action obligations required by the specifications set forth in 41 CFR 60-4.3(a) and its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade, and the Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor or from project to project for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, the Executive Order and the regulations in 41 CFR Part 60-4. Compliance with the goals will be measured against the total work hours performed. 3. The Contractor shall provide written notification to the Director of the Office of Federal Contract Compliance Programs (OFCCP) within 10 working days of award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the name, address, and telephone number of the subContractor; employer identification number of the subContractor; estimated dollar amount of the subcontract; estimated starting and completion dates of the subcontract; and the geographical area in which the subcontract is to be performed. 4. As used in this notice and in the contract resulting from this solicitation, the "covered area" is the State of Idaho, and Bonner County By: Bonner County, Idaho SNP LEGAL 7622 AD#371118 MARCH 14, 21, 2020

ORDINANCE NO. 599 ZONE CHANGE, ZC0009-19 AN ORDINANCE OF BONNER COUNTY, IDAHO, CITING ITS AUTHORITY, AND PROVIDING FOR THE AMENDMENT OF THE OFFICIAL ZONING MAP OF BONNER COUNTY BY THE RECLASSIFICATION OF LANDS GENERALLY LOCATED IN SECTION 17, TOWNSHIP 55 NORTH, RANGE 05 WEST, BOISE MERIDIAN, BONNER COUNTY IDAHO FROM AGRICULTURE/FORESTRY- 20 TO RURAL-5 AND PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, the Bonner County Planning and Zoning Commission did hold a public hearing on February 6, 2020 on the file ZC0009-19 request for a change in zoning designation according to the requirements for such hearings set forth at Section 67-6509, Idaho Code, and at Title 12, Bonner County Revised Code; and WHEREAS, the Bonner County Planning and Zoning Commission did find that the zone change request ZC0009-19 is in accordance with the Bonner County Comprehensive Plan and did recommend to the Board of County Commissioners that the zone change request be approved; and WHEREAS, the Board of County Commissioners did hold a public hearing on March 11, 2020 on the file ZC0009-19 request for a change in zoning designation according to requirements of such hearings set forth at Section 67-6509, Idaho Code and at Title 12 of the Bonner County Revised Code; and WHEREAS, the Board of County Commissioners did find that the zone change request ZC0009-19 is in accordance with the Bonner County Comprehensive Plan. NOW, THEREFORE BE IT ORDAINED, by the Board of County Commissioners that the following be and is hereby adopted as an ordinance of Bonner County, Idaho: SECTION 1: AUTHORITY This ordinance is adopted pursuant to authority granted to Bonner County at Chapter 65 of Title 67, Idaho Code. SECTION 2: AMENDING THE OFFICIAL ZONING MAP The Official Zoning Map of Bonner County, Idaho is hereby amended by the reclassification of the following described lands from Agriculture/Forestry-20 to Rural-5 LEGAL DESCRIPTION PARCEL A A PORTION OF THE NORTHWEST QUARTER OF SECTION 17, TOWNSHIP 55 NORTH, RANGE 05 WEST OF THE BOISE MERIDIAN, BONNER COUNTY, IDAHO; MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT THE NORTHWEST CORNER OF SAID SECTION 17; THENCE , SOUTH 89°59'08" EAST, 1320.00 FEET; THENCE, SOUTH 45°00'00" EAST, 919.2 FEET MORE OR LESS TO A POINT ON THE NORTH RIGHT-OF-WAY LINE OF THE COUNTY ROAD; THENCE ALONG SAID RIGHT-OF-WAT, SOUTH 45°13'02" WEST, 933.15 FEET; THENCE LEAVING SAID COUNTY ROAD RIGHT-OF-WAY, NORTH 45°00'00" WEST, 1849.3 FEET RETURNiNG TO THE POINT-OF-BEGINNING. CONTAINING 29.7 ACRES, MORE OR LESS; TOGETHER WITH AND SUBJECT TO EASEMENTS, RIGHTS-OF-WAY, COVENANTS, RESERVATIONS AND RESTRICTIONS OF RECORD AND IN VIEW LEGAL DESCRIPTION FOR PARCEL B A PORTION OF THE NORTHWEST QUARTER OF SECTION 17, TOWNSHIP 55 NORTH, RANGE 05 WEST OF THE BOISE MERIDIAN, BONNER COUNTY, IDAHO; MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT THE NORTHWEST CORNER OF SAID SECTION 17; THENCE, SOUTH 00°26'25 " WEST, 1320.00 FEET; THENCE , SOUTH 45°00'00" EAST, 919.5 FEET MORE OR LESS TO A POINT ON THE NORTH RIGHT-OF-WAY LINE OF A COUNTY ROAD; THENCE ALONG SAID NORTH RIGHT-OF-WAY LINE, NORTH 45°13'02" EAST, 940.53 FEET; THENCE LEAVING SAID RIGHT-OF-WAY LINE, NORTH 45°00'00" WEST, 1849.3 FEET MORE OR LESS RETURNING TO THE POINT OF BEGINNING. CONTAINING 29.9 ACRES, MORE OR LESS; TOGETHER WITH AND SUBJECT TO EASEMENTS, RIGHTS-OF-WAY , COVENANTS, RESERVATIONS AND RESTRICTIONS OF RECORD AND IN VIEW; SECTION 3: EFFECTIVE DATE This ordinance shall be in full force and effect upon its passage, approval and publication in one (1) issue of the Bonner County Daily Bee Newspaper, and upon the entry of the above described zoning reclassification upon the Official Zoning Map or a Supplemental Zoning Map in accordance with the provisions set forth at Chapter 4 of Title 12 of the Bonner County Revised Code. Regularly considered, passed and approved as an ordinance of Bonner County, Idaho, done this 11th day of March, 2020, upon the following roll call vote: Chairman Dan McDonald: Aye Commissioner Jeff Connolly: Commissioner Steve Bradshaw Aye BONNER COUNTY BOARD OF COMMISSIONERS /s/Dan McDonald, Chairman Jeff Connolly, Commissioner Absent /s/Steve Bradshaw, Commissioner ATTEST: Michael Rosedale, Clerk /s/Clair May By Clerk Date: March 11, 2020 SNP LEGAL 7626 AD#371366 MARCH 14, 2020

NOTICE OF HEARING ON NAME CHANGE (Adult or Emancipated Minor) IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BONNER IN RE:Christian Schmelzle- Clayton CASE NO. CV-09-20-0353 A Petition to change the name of Christian Schmelzle-Clayton, now residing in the City of Sagle, State of Idaho, has been filed in the District Court in Bonner County, Idaho. The name will change to Christian Murray.. The reason for the change in name is: It is my mother's last name. A hearing on the petition is scheduled for 11:00 o'clock a.m. on April 17, 2020 at the Bonner County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: March 2, 2020 JIM BRANNON, CLERK OF THE DISTRICT COURT By:/s/ Anne Marie Norling Deputy Clerk SNP LEGAL 7601 AD#369435 MARCH 7, 14, 21, 28, 2020

NOTICE OF TRUSTEE'S SALE To be sold for cash at a Trustee's Sale on June 29, 2020, 10:00 AM at the Bonner County Courthouse, 215 South First Avenue, Sandpoint, ID 83864, the following described real property situated in Bonner County, State of Idaho ("Real Property"): The North half of the Southwest Quarter of the Northwest Quarter of the Southeast Quarter, Section 19, Township 54 North, Range 4 West, Boise Meridian, Bonner County, Idaho Commonly known as: 145 Sierra Lane, Spirit Lake, ID 83869 Edward W. Defremery, as Trustor conveyed Real Property via a Trust Deed dated March 17, 2015, in favor of Mortgage Electronic Registration Systems, Inc. as nominee for Proficio Mortgage Ventures, LLC, its successors and assigns as Beneficiary, in which North Idaho Title Insurance, Inc. was named as Trustee. The Trust Deed was recorded in Bonner County, Idaho, on March 23, 2015, as Instrument No. 871229, of Official Records. The Deed of Trust was assigned for value as follows: Assignee: Finance of America Reverse, LLC Assignment Dated: September 12, 2019 Assignment Recorded: September 13, 2019 Assignment Recording Information: Instrument No. 945055 Shelly M. Espinosa is the Successor Trustee pursuant to a Substitution of Trustee recorded in the office of the Clerk and Recorder of Bonner, State of Idaho on September 19, 2019 at Instrument No. 945401, of Official Records. The Beneficiary has declared a default in the terms of said Deed of Trust due to the Trustor's failure to perform an obligation of the Security Instrument. By reason of said default, the Beneficiary has declared all sums owing on the obligation secured by said Trust Deed immediately due and payable. The total amount due on this obligation is the principal sum of $152,489.11. Beneficiary has elected, and has directed the Trustee to sell the above described property to satisfy the obligation. The sale is a public sale and any person, including the Beneficiary, may bid at the sale. The bid price must be paid immediately upon the close of bidding in cash or cash equivalents (valid money orders, certified checks or cashier's checks). The conveyance will be made by Trustee's Deed, without any representation or warranty, including warranty of title, express or implied, as the sale is made strictly on an as-is, where-is basis, without limitation, the sale is being made subject to all existing conditions, if any, of lead paint, mold or other environmental or health hazards. The Trustor, successor in interest to the Trustor, or any other person having an interest in the property, or any person named in IRC § 45-1506, has the right, at any time prior to the Trustee's Sale, to pay to the Beneficiary, or the successor in interest to the Beneficiary, the entire amount then due under the Deed of Trust and the obligation secured thereby (including costs and expenses actually incurred and attorney's fees) other than such portion of the principal as would not then be due had no default occurred and by curing any other default complained of herein that is capable of being cured by tendering the performance required under the obligation or to cure the default, by paying all costs and expenses actually incurred in enforcing the obligation and Deed of Trust with Successor Trustee's and attorney's fees. In the event that all defaults are cured the foreclosure will be dismissed and the foreclosure sale will be canceled. The scheduled Trustee's Sale may be postponed by public proclamation up to 30 days for any reason. If the Trustee is unable to convey title for any reason, the successful bidder's sole and exclusive remedy shall be the return of monies paid to the Successor Trustee and the successful bidder shall have no further recourse. The above Trustor are named to comply with IRC § 45-1506(4)(a). No representation is made that they are, or are not, presently responsible for this obligation. This is an attempt to collect a debt and any information obtained will be used for that purpose. Dated this 18th day of February, 2020. Shelly M. Espinosa Substitute Trustee 376 East 400 South, Suite 300, Salt Lake City, UT 84111 Telephone: 801-355-2886 Office Hours: Mon.-Fri., 8AM-5PM (MST) File No. 56281 SNP LEGAL 3199 AD#366897 FEBRUARY 22, 29, MARCH 7, 14, 2020

SUMMONS To: Dig Beats Productions LLC and Robert Terry Smith You have been sued by the State of Idaho, ex rel., Industrial Commission, the Plaintiff, in the District Court in and for Bonner County, Idaho, Case No. CV09-19-1308. The nature of the claim against you is for failure to maintain workers' compensation insurance. Any time after 21 days following the last publication of this summons, the court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the Case No., and paid any required filing fee to the Clerk of the Court at 215 S 1st Ave, Sandpoint, ID 83864, and the telephone number is 208 265-1446 and served a copy of your response on the Plaintiff's attorney, Blair D. Jaynes, at P.O. Box 83720, Boise, Idaho 83720-0041, telephone number 208 334-6028. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiff. If you wish legal assistance, you should immediately retain an attorney to advise you in this matter. DATED this 5th day of September 2019. Bonner County District Court By Michael W. Rosedale, Clerk SNP LEGAL 7607 AD#369782 MARCH 7, 14, 21, 28, 2020

NOTICE OF TRUSTEE'S SALE On Friday, the 26th day of June, 2020, at the hour of 10 o'clock A.M., of said day at the office of the Trustee at 301 Cedar Street, Ste. 203, Sandpoint, Idaho, 83864, Stephen T. Snedden, as Trustee, will sell at public auction, to the highest bidder, for cash (the Trustee is authorized to make a credit bid for the Beneficiary) in lawful money of the United States of America, all payable at the time of the sale, the following described real' property, situated in Bonner County, State of Idaho, to-wit: Lot 11 in Block 1 of Quail Ridge (Amended) according to the official plat thereof, filed in Book 8 of Plats at Page(s) 158, records of Bonner County, Idaho. For the purposes of compliance with Idaho Code 60-113, the Trustee address of 96 Cardinal Ln Spirit Lake, ID 83869 has been associated with this property. Said sale will be made without covenant or warranty regarding title, possession or encumbrances to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust made and entered into on August 16, 2019, by and among David Deed and Jessica Valle, as Grantors, and North Idaho Title Insurance, Inc., Trustee and Directed Trust Company FBO Robert Kincaid IRA, as Beneficiary; said Deed of Trust having been recorded on August 30, 2019 as Instrument No. 944403 Official records of Bonner County, Idaho. The above Grantors are named to comply with Idaho Code Section 45-1506(4) (a). No representation is made that they are or are not presently responsible for this obligation. The default for which this sale is to be made is failure of the Grantors to pay when due, monthly installments as set forth on the Note secured by said Deed of Trust. Monthly installments in the amount of $442.73, which includes principal, interest and escrow impounds, is due for September 30, 2019 and the 30' day of each and every month thereafter until paid. Interest due as of January 15, 2020 is in the amount of $1151.64 and continues to accrue at the rate of 9% percent per annum. ALL AMOUNTS are now due and payable along with all costs and fees associated with this foreclosure. Late charges are owed in an amount exceeding $70.84. The principal balance is $43,650.00. Dated this 17 day of February, 2020. /s/Stephen T. Snedden, Successor Trustee SNP LEGAL 3200 AD#366903 FEBRUARY 22, 29, MARCH 7, 14, 2020